《Fidic合同(英文)通用条款(EPC).doc》由会员分享,可在线阅读,更多相关《Fidic合同(英文)通用条款(EPC).doc(87页珍藏版)》请在三一办公上搜索。
1、General ConditionsGeneral Provisions1.1 Definitions In the Conditions of Contract (these Conditions), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meanings stated. Words indicating persons or parties include corporations and oth
2、er legal entities, except where the context requires otherwise.1.1.1 The Contract1.1.1.1 Contract means the Contract Agreement, these Conditions, the Employers Requirements, the Tender, and the further documents (if any) which are listed in the Contract Agreement.1.1.1.2 Contract Agreement means the
3、 contract agreement referred to in Sub-Clause 1.6 Contract Agreement, including any annexed memoranda.1.1.1.3 Employers Requirements means the document entitled employers requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract.
4、Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.1.1.1.4 Tender means the Contractors signed offer for the Works and all other documents which the Contractor submitted therewith (other than these Conditions and the Employers Requirements, if so
5、 submitted), as included in the Contract1.1.1.5 Performance Guarantees and Schedule of Payments mean the documents so named (if any), as included in the Contract.1.1.2 Parties and Persons1.1.2.1 Party means the Employer or the Contractor, as the context requires.1.1.2.2 Employer means the person nam
6、ed as employer in the Contract Agreement and the legal successors in title to this person.1.1.2.3 Contractor means the person(s) named as contractor in the Contract Agreement and the legal successors in title to this person(s).1.1.2.4 Employers Representative means the person named by the Employer i
7、n the Contract or appointed from time to time by the Employer under Sub-Clause 3.1 The Employers Representative, who acts on behalf of the Employer.1.1.2.5 Contractors Representative means the person named by the Contractor in the Contract or appointed from time to time by the Contractor under Sub-C
8、lause 4.3 Contractors Representative, who acts on behalf of the Contractor.1.1.2.6 Employers Personnel means the Employers Representative, the assistants referred to in Sub-Clause 3.2 Other Employers Personnel and all other staff, labour and other employees of the Employer and of the Employers Repre
9、sentative; and any other personnel notified to the Contractor, by the Employer or the Employers Representative, as Employers Personnel.1.1.2.7 Contractors Personnel means the Contractors Representative and all personnel whom the Contractor utilises on Site, who may include the staff, labour and othe
10、r employees of the Contractor and of each Subcontractor; and any other personnel assisting the Contractor in the execution of the Works.1.1.2.8 Subcontractor means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal
11、successors in title to each of these persons.1.1.2.9 DAB means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 Appointment of the Dispute Adjudication Board or Sub-Clause 20.3 Failure to Agree Dispute Adjudication Board.1.1.2.10 FIDIC means th
12、e Federation Internationale des Ingenieurs-Conseils the international federation of consulting engineers.1.1.3 Dates, Tests, Periods and Completion1.1.3.1 Base Date means the date 28 days prior to the latest date for submission of the Tender.1.1.3.2 Commencement Date means the Commencement of Works,
13、 unless Agreement. date notified under Sub-Clause 8.1otherwise defined in the Contract1.1.3.3 Time for Completion means the time for completing the Works or aSection (as the case may be) under Sub-Clause 8.2 Time for Completion, as stated in the Particular Conditions (with any extension under Sub-Cl
14、ause 8.4 Extension of Time for Completion), calculated from the Commencement Date.1.1.3.4 Tests on Completion means the tests which are specified in Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 Tests on Completion before the Works or a Sec
15、tion (as the case may be) are taken over by the Employer1.1.3.5 “Taking-Over Certificate means a certificate issued under Clause 10 Employers Taking Over1.1.3.6 Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out under Clause 12 Tests after C
16、ompletion after the Works or a Section (as the case may be) are taken by the Employer1.1.3.7 Defects Notification Period means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 Completion of Outstanding Work and Remedying Defects, as stated in the
17、Particular Conditions (with any extension under Sub-Clause 11.3 Extension of Defects Notification Periodcalculated from the date on which the Works or Section is completed as certified under Sub-Clause 10.1 Taking Over of the Works and Sections. If no such period is stated in the Particular Conditio
18、ns, the period shall be one year.1.1.3.8 Performance Certificate means the certificate issued under Sub-Clause 11.9 Performance Certificate.1.1.3.9 day means a calendar day and year means 365 days.1.1.4 Money and Payments1.1.4.1 Contract Price means the agreed amount stated in the Contract Agreement
19、 for the design, execution and completion of the Works and the remedying of any defects, and includes adjustments (if any) in accordance with the Contract.1.1.4.2 Cost means all expenditure reasonably incurred (or to be incurred) by the Contractor, whether on or off the Site, including overhead and
20、similar charges, but does not include profit.1.1.4.3 Final Statement means the statement defined in Sub-Clause 14.11 Application for Final Payment.1.1.4.4 Foreign Currency means a currency in which part (or all) of the Contract Price is payable, but not the Local Currency.1.1.4.5 Local Currency mean
21、s the currency of the Country.1.1.4.6 Provisional Sum means a sum (if any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Materials or services under Sub-Clause 13.5 Provisional Sums1.1.4.7 Retention Money means the acc
22、umulated retention moneys which the Employer retains under Sub-Clause 14.3 Application for Interim Payments and pays under Sub-Clause 14.9 Payment of Retention Money1.1.4.8 Statement means a statement submitted by the Contractor as part of an application for payment under Clause 14 Contract Price an
23、d Payment.1.1.5 Works and Goods1.1.5.1 Contractors Equipment means all apparatus, machinery, vehicles and other things required for the execution and completion of the Works and the remedying of any defects. However, Contractors Equipment excludes Temporary Works, Employers Equipment (if any), Plant
24、 Materials and any other things intended to form or forming part of the Permanent Works.1.1.5.2 Goods means Contractors Equipment, Materials, Plant and Temporary Works, or any of them as appropriate.1.1.5.3 Materials means things of all kinds (other than Plant) intended to form or forming part of th
25、e Permanent Works, including the supply-only materials (if any) to be supplied by the Contractor under the Contract.1.1.5.4 Permanent Works means the permanent works to be designed and executed by the Contractor under the Contract.1.1.5.5 Plant means the apparatus, machinery and vehicles intended to
26、 form or forming part of the Permanent Works.1.1.5.6 Section means a part of the Works specified in the Particular Conditions as a Section (if any).1.1.5.7 Temporary Works means all temporary works of every kind (other than Contractors Equipment) required on Site for the execution and completion of
27、the Permanent Works and the remedying of any defects.1.1.5.8 Works mean the Permanent Works and the Temporary Works, or either of them as appropriate.1.1.6 Other Definitions1.1.6.1 Contractors Documents means the calculations, computer programs and other software, drawings, manuals, models and other
28、 documents of a technical nature supplied by the Contractor under the Contract; as described in Sub-Clause 5.2 Contractors Documents.1.1.6.2 Country means the country in which the Site (or most of it) is located where the Permanent Works are to be executed.1.1.6.3 Employers Equipment means the appar
29、atus, machinery and vehicles (if any) made available by the Employer for the use of the Contractor in the execution of the Works, as stated in the Employers Requirements; but does not include Plant which has not been taken over by the Employer.1.1.6.4 Force Majeure is defined in Clause 19 Force Maje
30、ure.1.1.6.5 Laws means all national (or state) legislation, statutes, ordinances and other laws, and regulations and by-laws of any legally constituted public authority.1.1.6.6 Performance Security means the security (or securities, if any) under Sub-Clause 4.2 Performance Security1.1.6.7 Site means
31、 the places where the Permanent Works are to be executed and to which Plant and Materials are to be delivered, and any other places as may be specified in the Contract as forming part of the Site. 1.1.6.8 Variation means any change to the Employers Requirements or the Works, which is instructed or a
32、pproved as a variation under Clause 13 Variations and Adjustments1.2 InterpretationIn the Contract, except where the context requires otherwise:(a) words indicating one gender include all genders; (b) words indicating the singular also include the plural and words indicating the plural also include
33、the singular;(c) provisions including the word agree, agreed or agreement require the agreement to be recorded in writing, and (d) written or in writing means hand-written, type-written, printed or electronically made, and resulting in a permanent record.The marginal words and other headings shall n
34、ot be taken into consideration in the interpretation of these Conditions.1.3 CommunicationsWherever these Conditions provide for the giving or issuing of approvals, certificates, consents, determinations, notices and requests, these communications shall be: (a) In writing and delivered by hand (agai
35、nst receipt), sent by mail or courier, or transmitted using any of the agreed systems of electronic transmission as stated in the Particular Conditions; and (b) delivered, sent or transmitted to the address for the recipients communications as stated in the Contract. However: (i) if the recipient gi
36、ves notice of another address, communications shall thereafter be delivered accordingly; and (ii) if the recipient has not stated otherwise when requesting an approval or consent, it may be sent to the address from which the request was issuedApprovals, certificates, consents and determinations shal
37、l not be unreasonably withheld or delayed.1.4 Law and LanguageThe Contract shall be governed by the law of the country (or other jurisdiction) stated in the Particular Conditions. If there are versions of any part of the Contract which are written in more than one language, the version which is in t
38、he ruling language stated in the Particular Conditions shall prevail. The language for communications shall be that stated in the Particular Conditions. If no language is stated there, the language for communications shall be the language in which the Contract (or most of it) is written.1.5 Priority
39、 of Documents The documents forming the Contract are to be taken as mutually explanatory of one another. For the purposes of interpretation, the priority of the documents shall be in accordance with the following sequence:See Particular Conditions1.6 Contract Agreement The Contract shall come into f
40、ull force and effect on the date stated in the Contract Agreement. The costs of stamp duties and similar charges (if any) imposed by law in connection with entry into the Contract Agreement shall be borne by the Employer.1.7 Assignment Neither Party shall assign the whole or any part of the Contract
41、 or any benefit or interest in or under the Contract. However, either Party: (a) may assign the whole or any part with the prior agreement of the other Party, at the sole discretion of such other Parry, and(b) may, as security in favour of a bank or financial institution, assign its right to any mon
42、eys due, or to become due, under the Contract.1.8 Care and Supply of Document Each of the Contractors Documents shall be in the custody and care of the Contractor, unless and until taken over by the Employer. Unless otherwise stated in the Contract, the Contractor shall supply to the Employer six co
43、pies of each of the Contractors Documents.The Contractor shall keep, on the Site, a copy of the Contract, publications named in the Employers Requirements, the Contractors Documents, and Variations and other communications given under the Contract. The Employers Personnel shall have the right of acc
44、ess to all these documents at all reasonable timesIf a Party becomes aware of an error or defect of a technical nature in a document which was prepared for use in executing the Works, the Party shall promptly give notice to the other Party of such error or defect.1.9 ConfidentialityBoth Parties shal
45、l treat the details of the Contract as private and confidential, except to the extent necessary to carry out obligations under it or to comply with applicable Laws. The Contractor shall not publish, permit to be published, or disclose any particulars of the Works in any trade or technical paper or e
46、lsewhere without the previous agreement of the Employer.1.10 Employers Use of Contractors DocumentsAs between the Parties, the Contractor shall retain the copyright and other intellectual property rights in the Contractors Documents and other design documents made by (or on behalf of) the Contractor
47、.The Contractor shall be deemed (by signing the Contract) to give to the Employer a non-terminable transferable non-exclusive royalty-free license to copy, use and communicate the Contractors Documents, including making and using modifications of them. This license shall: (a) apply throughout the actual or intended working life (whichever is longer) of the relevant parts of the Works (b) entitle any person in proper possession of the relevant part of the Works to copy, use and communicate the Contractors Documents for the purposes of completing, operating, maint